Wahlcometroflex v. Westar Energy

by
Westar Energy was an electric company based in Topeka, Kansas that owned several sources of electricity, including the Jeffrey Energy Center (JEC). The JEC was a coal-fired power plant composed of three units: Unit 1, Unit 2, and Unit 3. In 2005, Westar began a project to upgrade the JEC’s existing flue gas desulfurization (FGD) system. Wahlcometroflex Inc. (Wahlco) was a Delaware corporation that designed and manufactured a number of products including FGD dampers. On December 22, 2006, Westar and Wahlco entered into a contract under which Wahlco agreed to manufacture and deliver dampers to Westar for Units 1, 2, and 3. This case involved a dispute over the meaning and application of a liquidated damages in that contract provision under Kansas law. The district court held that Westar did not need to establish that Wahlco's late delivery of the equipment actually delayed Westar’s production schedule in order to recover contractual liquidated damages. Finding no error in that judgment, the Tenth Circuit affirmed. View "Wahlcometroflex v. Westar Energy" on Justia Law